General terms and conditions

1. Unless protested by registered letter within 5 working days after
receipt of the invoice, it shall be deemed accepted by the customer.

2. The present contract is concluded at the permanent place of business of the
seller, being at the address: Kleinewinkellaan 26a, 1853 Grimbergen.

3. The parties jointly and severally undertake to fulfil their obligations.

4. Retention of title clause: The contractor/seller retains full title to all materials and
ownership of all materials and goods supplied by him until final payment for the goods has been made.
until the moment of final payment of the entire contract or sale price.

5. The planned terms of execution can be changed by both parties and within
5. The planned dates of execution can be changed by both parties within reasonable limits insofar as a sound reason is shown, such as
5. The periods of execution provided for may be changed by either party within reasonable limits insofar as a good reason is shown, such as, for example, serious illness of
parties or their relatives and staff, longer delivery or
execution deadlines of third parties, unexpected circumstances delaying the
performance of the work, etc.

6. The prices given are only valid for a period of 30 days, counting
date of the offer.

7. All invoices are in principle payable in cash unless otherwise agreed.
In the latter case, the invoice must be paid within 7 days of its creation.
of its creation. In any event, bank charges shall be borne by the
paying party. In the event of late payment, interest on arrears shall accrue automatically and by operation of law.
interest on arrears of 1% per month. Furthermore, a
compensation for non-payment will also be due, conventionally and
fixed at 12% of the principal sum with a minimum of €75.
75€. In the latter case, Huysmans-De Backer bv shall also be entitled to
transfer the file to an external collection agency. The costs of
this external procedure will be entirely at the defendant's expense.

8. In the event of termination of the agreement by the buyer, an amount equal to 1/3 of the amount due as compensation for
compensation, an amount equal to 1/3 of the agreed
agreed price, with as a minimum the price already paid or advance payment.

9. In case of disputes, the Courts in Brussels are competent, at the choice of the plaintiff
or those of the defendant's place of residence.

10. The contractor provides for his liability for material damage up to 125000
euro. If projects exceed this, the buyer is responsible for taking out
taking out additional insurance.